Loading...
Serving Eastvale, CA and surrounding areas. (909) 479-6940
Effective Date: January 1, 2026
By accessing or using the website at eastvalefenceanddeck.com, by submitting a contact or estimate request form, or by engaging Advanced Eastvale Fence & Deck ("we," "us," or "our") for services, you agree to be bound by these Terms and Conditions. If you do not agree to these terms, please do not use this website or request our services.
These Terms and Conditions apply to all visitors, customers, and others who interact with our website or contact us for services.
Advanced Eastvale Fence & Deck is a licensed deck builder and outdoor structure contractor serving Eastvale, CA and the surrounding Inland Empire. Our services include, but are not limited to, custom deck design and construction, composite and wood deck installation, fence installation, pergola construction, patio covers, and related outdoor living projects.
All services are subject to availability, site conditions, permit requirements, and a mutually agreed-upon written contract or work order before work begins. Visiting this website or submitting a form does not create a service agreement or obligation on either party.
All estimates provided by Advanced Eastvale Fence & Deck are based on information available at the time of the estimate, including site conditions observed during a walk-through, materials selected, and the scope of work described. Estimates are not binding quotes unless confirmed in a written agreement signed by both parties.
Final pricing is set in a written contract. The contract price covers the agreed scope of work. Changes to the scope - including additions, material upgrades, or modifications discovered during construction - will be addressed through a written change order that both parties must approve before the additional work proceeds. We do not perform out-of-scope work without prior written authorization.
Permit fees, HOA submission fees, and material price fluctuations not known at the time of quoting may affect final pricing. Any such adjustments will be communicated to you before they are applied.
Project start dates are estimates based on permit timelines, material availability, and current workload. We will communicate any changes to your scheduled start date as soon as we are aware of them.
If you need to cancel or postpone a project after a contract has been signed, please notify us in writing as soon as possible. Cancellation terms, including any deposit requirements or cancellation fees, are specified in your written contract. Deposits may be non-refundable if materials have already been ordered or permits have been filed on your behalf.
We reserve the right to delay or reschedule work due to weather conditions, permit delays, supply chain issues, or other circumstances outside our control. We will notify you promptly in these situations and work with you to establish a new timeline.
Payment terms are specified in your written contract. Typical arrangements include a deposit at contract signing, progress payments at defined milestones, and a final payment upon project completion. We accept payment methods as described in your contract.
Final payment is due upon completion of the work described in the contract. Withholding final payment for reasons unrelated to incomplete or defective work as defined in the contract is not permitted. Disputes regarding the quality of work should be raised in writing before final payment is withheld.
Accounts that are past due may be subject to late fees as specified in your contract. We reserve the right to suspend work on a project if payments are not made according to the agreed schedule.
Many deck and fence projects in Eastvale, CA require permits from local building authorities, and some neighborhoods require prior approval from a homeowners association. We will identify permit requirements based on the proposed scope of work and handle permit applications on your behalf as part of the project.
You are responsible for disclosing any HOA rules, easements, setback requirements, utility line locations, or other property-specific restrictions that may affect the project. Failure to disclose known restrictions may result in additional costs or required modifications that are your responsibility.
We stand behind our workmanship. Specific warranty terms are described in your written contract and may vary by project type and materials used. Manufacturer warranties on materials such as composite decking or railings are separate from our workmanship warranty and are governed by the respective manufacturer's terms.
Warranty claims must be submitted in writing within the warranty period. Our warranty does not cover damage caused by misuse, neglect, acts of nature, modifications made by others, or normal wear and tear.
To the fullest extent permitted by applicable law, Advanced Eastvale Fence & Deck shall not be liable for any indirect, incidental, special, consequential, or punitive damages arising from the use of our website, our services, or any work performed under a contract with us.
Our total liability to you for any claim arising out of or related to our services shall not exceed the total amount paid by you for the specific work giving rise to the claim.
Nothing in these terms limits our liability for gross negligence, willful misconduct, or any liability that cannot be excluded under applicable law.
The content on eastvalefenceanddeck.com is provided for general informational purposes only. While we make reasonable efforts to keep the information current and accurate, we make no representations or warranties of any kind, express or implied, about the completeness, accuracy, or reliability of the content. Any reliance you place on information from this website is at your own risk.
We reserve the right to modify or remove content from our website at any time without notice.
We prefer to resolve any disputes directly and informally. If you have a concern about our services or a project, please contact us first at quotes@eastvalefenceanddeck.com or (909) 479-6940. Most issues can be resolved quickly through direct communication.
If a dispute cannot be resolved informally, the parties agree to attempt mediation before pursuing litigation. Any unresolved legal disputes shall be subject to binding arbitration or litigation in the appropriate courts located in California, as permitted by applicable law.
These Terms and Conditions are governed by and construed in accordance with the laws of the State of California, without regard to its conflict of law provisions. Any legal action or proceeding arising under these terms shall be brought exclusively in the courts located in California.
We may update these Terms and Conditions from time to time. When we make changes, we will update the effective date at the top of this page. Your continued use of our website after any changes are posted constitutes your acceptance of the revised terms. We encourage you to review this page periodically.
If you have questions about these Terms and Conditions, please contact us: